Betingelser for utførelse av arbeidene

Betingelser for utførelse av arbeidene

1. Bestilleren bestiller, og leverandøren aksepterer ordren for utførelse.

2. Utførelse av ordre vil bli innledet med hensiktsmessige oppmålinger av byggherren på byggherrens anlegg og utarbeidelse av rekkverkskonstruksjonen av entreprenøren. Prosjektet vil også omfatte avtaler mellom partene, og det er derfor svært viktig å kontrollere bestillerens avtaler og at prosjektet er i samsvar med disse, fordi det på grunnlag av dette vil bli produsert enkeltelementer som ikke kan endres/forbedres etter at de er produsert.

3. KONTRAKTENS GJENSTAND :
Utførelse av rekkverk i henhold til tegningene som er sendt etter målinger og akseptert av kunden og tilbudet med den eldste datoen (sendt på e-post).

4. TIDSFRIST FOR FERDIGSTILLELSE :
Implementeringen av rekkverksdesignet vil finne sted innen 7 uker fra det øyeblikket vi aksepterer designene og betaler de nødvendige forskuddene/betalingene. Tilfeldige situasjoner er ikke entreprenørens feil og kan påvirke ferdigstillelsesdatoen.

5. FORSKUDD/BETALINGER FOR BESTILLINGEN:
I Forskuddsbetaling for påbegynnelse av utførelsen 30% av verdien av bestillingen, ikke mindre enn 1000 PLN.
II Betaling av det resterende beløpet av den totale verdien av bestillingen – før lossing av varene.

6. Proformafaktura, tegninger (prosjekter) som er godkjent av bestilleren, utgjør en integrert del av kontrakten.

7. Grunnlag for ny beregning   tilbudet (proformafakturaer) er et utkast fra leverandøren. Det etterberegnede tilbudet vil være i samsvar med de faktiske forhold.

8. Bestillingen vil bli utført på grunnlag av det prosjektet som bestilleren har godkjent, og som vi sender til bestilleren etter oppmålingene som bestilleren har foretatt, er bestilleren forpliktet til å konsultere prosjektet med de enkelte entreprenørene på byggeplassen som har betydning for størrelsen på stedet der rekkverket skal plasseres.

9. Bestiller er forpliktet til å informere deg om eventuelle endringer mellom befaring og oppmåling. Ved endringer som leverandøren ikke blir informert om, og som vil påvirke bestillingen, skal merkostnadene bæres av bestilleren.

10. Bestiller er forpliktet til å informere entreprenøren om muligheten for å komme inn på byggeplassen eller ikke, hvis entreprenøren tidligere har rapportert at han har til hensikt å komme med varene.

11. Verdien av alt arbeid utført av leverandøren knyttet til korrekt utførelse av ordren og materialbruken er beregnet og inkludert i proformafakturaen, som er en integrert del av kontrakten. Økning av arbeidsomfanget, endring av mengden materialer som brukes, endring av designforutsetninger er faktorer som påvirker prisen og er grunnlag for ny beregning av ordren.

12. Under gjennomføringen av bestillingen skal leverandøren får tilgang til anleggene for et team av egne ansatte, og alle forberedelser knyttet til byggherrens klargjøring av undergrunnen er fullført. Byggherren skal sørge for at entreprenøren har en parkeringsplass og et sted der materialet kan losses på en sikker måte.

13.Leverandøren har det fulle og hele ansvaret for egne ansatte innen helse og sikkerhet under utførelsen av oppdraget på oppdragsgivers anlegg.

14. Kjøperen skal foreta betalingen for de enkelte fasene av leverandørens arbeid, og leverandøren skal utstede passende dokumenter som bekrefter disse betalingene.

15.For det utførte arbeidet og materialet som er brukt, gir leverandøren bestilleren 1 års garanti.

16. Strukturens sveiser er synlige. Etter galvanisering kan du se sveisepunktet.

17. Med punkttrykk, rutene kan bøyes i samsvar med standardene – nedbøyningen avhenger av tykkelsen på glasset, størrelsen og trykkraften.

18. Usynlig mangel fra en avstand på 2 meter er ikke en produktfeil.

19. Varer til som er betalt av kjøperen, forblir leverandørens eiendom og er ikke gjenstand for krav.

20. Jeg er innforstått med til å fotografere objektet vederlagsfritt. Samtidig samtykker jeg i å bruke fotomaterialet vederlagsfritt for RAPDACH Sp. z o.o.s behov, samtidig som jeg respekterer personvernet og anonymiteten til eieren av objektet.

21. Kompetent domstol domstol i Nowy Sącz for å løse tvister.

Conditions for the implementation of the balustrade with assembly on the side of the RAPDACH company

1. The Ordering Party commissions, and the Contractor accepts an order with a specific number for execution

2. Execution of the order preceded will be making the appropriate measurements by the Contractor on the Employer’s facilities and preparing the assembly project. The project will also include arrangements between the parties, so it is very important to check the arrangements and compliance of the project, because on its basis, individual elements will be produced that cannot be changed/improved after their production.

3. SUBJECT OF THE CONTRACT:
Execution and assembly of railings in accordance with the submitted after measurements and accepted designs and offer (email contact)

4. TIME LIMIT FOR COMPLETION :
The project will be implemented within 7 weeks from the moment of accepting the projects and paying the required advances/payments. Delay in the preparation of the front of the works (place of the contract) by the ordering party for the assembly of railings results in the extension of the assembly deadline. Random situations are not the contractor’s fault and may affect the completion date.

5. ADVANCES/PAYMENTS FOR THE ORDER:
1st advance payment for commencement of execution 30% of the value of the order, not less than PLN 1,000
2nd advance payment for imported materials and employee delegation costs (before unloading the goods at the construction site)
III payment for completed orders (assembly) – payable after completion of work

6. Proforma invoice , drawings approved by the Employer and a measurement survey
are an integral part of the contract.

7. Basis for recalculation of the offer (Proforma invoices) is a design made by the Contractor after prior measurements and surveys. The recalculated offer will be consistent with the facts

8. The order will be fulfilled on the basis of the project approved by the ordering party, which we will send to the ordering party after the measurements have been made, the ordering party is obliged to consult the project with individual contractors who have an impact on the size of the place where the railing is to be placed.

9. The Ordering Party is obliged inform about changes between the survey and measurements and the preparation made before the arrival of the fitters, if any. In the case of changes of which the Contractor will not be informed and they will affect the order, additional costs shall be borne by the ordering party.

10. The Ordering Party is obliged to informing the contractor about the possibility of entering the construction site or lack of it, if the contractor has previously notified that he intends to come for assembly.

11. The value of all the Contractor’s work related to the proper execution of the order and the materials used has been calculated and included in the proforma invoice, which is an integral part of the contract. Increasing the scope of work, changing the amount of materials used, changing design assumptions are factors that affect the price and are the basis for re-calculation of the order.

12. During the execution of the order, the Contractor receives access to the facilities for a team of own employees, and all arrangements related to the preparation of the subgrade by the Employer have been completed. The Employer shall provide the contractor with a parking space and a place where the material can be safely unloaded.

13. The contractor bears full responsibility  for own employees in the field of health and safety protection during the performance of the order on the Employer’s construction facilities.

14. The Purchaser will make the payment for individual stages of the Contractor’s work, and the Contractor shall issue appropriate documents confirming these payments.

15. For the work done and the material used, the Contractor grants the Ordering Party a 1-year warranty.

16. The welds of the structure are visible. After galvanizing, you can see the welding spot.

17. The mounting surface should be simple, if it is not otherwise, the contractor will make every effort to perform the assembly so that the whole thing comes out aesthetically. We do not take responsibility for the unevenness of the walls and the substrate previously prepared by the customer.

18. The contractor sets the balustrade horizontally , at the customer’s request, the balustrade can be sloped in accordance with the curvature of the balcony. This should be taken into account in the drawings.

19. With point pressure, the panes can bend in accordance with the standards – the deflection depends on the thickness of the glass, its size and the force of pressure.

20. Scarcity invisible from a distance of 2 meters is not a product defect.

21. The Employer will provide the fitters access to the toilet and electricity at your own expense.

22.Ordering Party or authorized person by Him, undertakes to stay at the assembly site at the end of the work. During the absence of the Employer or a person authorized by him, he authorizes the Contractor to unilaterally accept the works.

23. The goods remain the property of the Contractor until payment by the Ordering Party and are not subject to complaint.

24. I consent to the object being photographed free of charge. At the same time, I consent to the free use for the needs of RAPDACH Sp. z o. o. photographic materials without infringing the privacy and anonymity of the owner of the facility.

25. Competent court disputes are settled by the court in Nowy Sącz.

26. In accordance with point 17 the mounting location should be prepared for proper installation. In the event of a situation in which a Rapdach employee performs activities not related to the direct installation of Rapdach products, the cost of a man-hour of one employee, i.e. PLN 150 net, is covered by the CONTRACTING PARTY

27. The Ordering Party authorizes the Contractor  to issue VAT invoices without the obligation to sign.

Rapdach Sp. Z O.O
Ptaszkowa 957
33-333 Ptaszkowa
Tel: +48 888 444 517